INDENTURE WITNESSED AS FOLLOWS
1.0 Name of the ProjectThat the Name of the project shall be “Nibash Jotsna†in consonance with name of its Developer.
2.0 Engagement & Consideration2.1 That in Consideration that the Developer shall sell & transfer and the 2nd Party shall purchase, subject to the terms of this 0.78382 ( zero point seven eight three eight two ) Katha or 1.2933 Decimal undivided, un remarketed project-land as described in Schedule-B hereto at a price herein after mentioned.
2.2 That the cost of construction of the demised Apartment & Car-ports shall include, in addition to the cost of structural construction thereof, the proportionate cost of development of the project-site, construction of internal roads, passages, pavements, stairs, drains, under ground and over ground water reservoirs and installation of water supply line, lift, standby generator, sewerage line, gas supply pipeline and water lifting pumps with electric motors as per Plan and standard Specifications.
2.3 That the Developer shall use quality-materials in the construction of the Project, particularly the Apartment and Car-port of the 2nd Party, with modern features as mentioned in the Prospectus and shall complete the construction with good workmanship.
2.4 That the 2nd Party shall, without prejudice to any other provision of this instrument and without reference to the actual market value of the land and cost of construction to be incurred, pay the Developer a sum of TK. 65,75,000/ -(Taka Sixty Five Lac Seventy Five Thousand) only for the properties described in Schedule-B & C below as the price of his allotted share of Project Land and as the cost of construction of Apartment, Car-port and common facilities as well as the service charges of the Developer. However the price will be settle at actual during handover based on final measurement of floor space and common space based on the rate of 2750.00 Tk per Sft and 250,000.00 Tk per Car Park.
3.0 Payment ModalityThat since, out of the payable sum of TK.65,75,000/ (Taka Sixty Five Lac Seventy Five Thousand) only, the 2nd Party has already paid Booking money & Down payment TK. 13,15,000/ -(Thirteen Lac Fifteen Thousand Taka) only, the receipt of which the Developer hereby acknowledges, the remaining amount of TK. 52,60,000/ -(Fifty Two Lac Sixty Thousand Taka) only shall be payable, subject to the provision of Clause no. 5.0 bellow, by the 2nd Party to the Developer as per following payment slab:
Grade Beam Casting 657,000.00 Tk
1st Slab Casting Beam Stage 657,000.00 Tk
2nd Slab Casting Stage 657,000.00 Tk
3rd Slab Casting Stage 657,000.00 Tk
4th Slab Casting Stage 657,000.00 Tk
5th Slab Casting Stage 657,000.00 Tk
6th Slab Casting Stage 657,000.00 Tk
During the time of Handover 657,000.00 Tk Note: The increased or decreased cost based on actual measurement of floor space and common space will be adjusted with the last payment during the time of handover.
4.0 Improvement Cost4.1 That excepting what is provided hereunder, the 2nd Party shall have no entitlement to do or cause to be done any change or alteration in the basic structure and external look of his Apartment and location of his Car-port so as to cause the same loose strength or diminish in value and quality or look externally different from other Apartments of the Project.
4.2 That is, if the 2nd Party wants to have any internal modification in his Apartment he shall inform the Developer of the proposed modificationin writing within such time as the Developer shall determine and upon receipt of such request the Developer will consider its feasibility in consultation with the Architectural & Structural Engineer. The 2nd party shall then be asked to sit with the companies architect to make changes in the room(s) size and orientation of his flat and shall finalize a plan for his portion without making changes in common facilities, plumbing lines and exterior of the building. In case the modification involves additional cost, the developer shall assess the additional cost involvement (if any) and convey to the 2nd Party the amount and date of payment thereof. No request for modification shall be entertained after the expiry of the time fixed therefore.
4.3 That if the 2nd Party desire to use some improved finishing materials instead of the ones selected by the Developer, the 2nd Party shall have option to select them from the list of optional items subject to his agreeing to pay the additional cost therefore as per assessment to be made by the Developer andpayment thereof within the time-frame made by the Developer. The Developer shallunder no circumstance entertain any request for optional works without the request and payment being made within and in accordance with the time-frame.
5.0 Default & Consequence5.1 That it shall be obligatory on the part of the 2nd Party to make all payments strictly in accordance with the Payment Schedule and within the time specified therefore failing which the Developer shall have a right of action and the 2nd Party shall be liable as set forth below.
5.2 That if the 2nd Party fails to pay any installment within the time fixed therefore, he shall be entitled, only once to pay the same within 30 (Thirty days of the date of default, along with such other installments which may, in the meantime, be found due, with a Default-Charge @ 2% (two per centum) per menses on the defaulted amount. Default-Charge shall be chargeable on every day of delay. This privilege shall strictly be limited to default in payment of only one installment.
5.3 That after the expiry of 30 (thirty ) days from the date of default in payment of any single installment, the Developer shall be at liberty to the 2nd Party at his last-known address a 15 (fifteen) days prior Notice under registered post demanding payment of the defaulted amount on or before the expiry days from the date of default and to cancel the allotment and resign this deal altogether and to re-allot the Apartment, Car-port and land concerned to any other 2nd Party of Developer’s free choice of the deal shall have the effect of rending a documents between the parties hereto, registered or unregistered, entirely null and void for all purposes.
5.4 That in the event of cancellation of the Allotment and recession of the deal, the 2nd Party shall be entitled to refund of the money already paid by the latter, excluding TK.1,00,000.00 (Taka One Lac) only within 120 (one hundred twenty) days from the date of such cancellation subject to the 2nd Party immediate executing and / or registering all such written instruments in favor of the Land-owners and/or the Developer as shall be demanded by the latter in proof of his acceptance of the cancellation of the Allotment and recession of the deal effectually and completely for all purposes.
6.0 Cost of utilitiesThat the Developer shall arrange to install separate Meters for gas and electricity in the demised Apartment for and in the name of the 2nd Party. The cost of installation, including the connection fees, security deposit and incidental charges relating thereto, will be initially paid by the Developer to the concerned authorities. The 2nd Party shall reimburse the same to the Developer in proportion to his share immediately after the incurring of such expenses as per the demand of the Developer.
7.0 Deed of TransferThat the developer is empowered to perform by itself or the Land-owners shall, whenever be requested by the Developer in performance of this Agreements, execute and register a Deed of Transfer and execute or endorse instruments ancillary thereto in favor of the 2nd Party in respect of the invisible national share of the Project Land allotted to the latter (vide Schedule –B). The costs and expenses at actual on account of preparation and processing of the documents, non-judicial stamps and cartridge papers, registration, Taxes including Gain-tax payable by the Vendors and all other incidental charges shall be payable exclusively by the 2nd Party at least 15 (fifteen) Days before execution and /or registration of such documents of transfer.
7.1 That the 2nd party is hereby agreed to complete the registration process as soon as possible after completion of full payment in schedule time or earlier and has agreed to complete the registration no later than three months of handover of his apartment (s).
8.0 Delivery of Possession 8.1 That the Developer shall formally deliver physical possession of the Apartment and Car-port of 2nd Party’s entitlement in his/her/their favor only after completion of the construction of the Project within declared time in all respects and receipt of all payments under this deal or Agreement between the parties hereto in full whichever is later. Possession shall be delivered under an instrument of delivery to be signed by the Developer and the 2nd Party if otherwise developer shall pay equivalent monthly rent to the 2nd party till handover. After hand over the Apartment the developer will registry the Apartment to the 2nd party within 12 months and the related registration cost will be paid by the 2nd party.
8.2 That the Developer shall give a Notice in writing to the 2nd Party to take vacant possession of the demised Apartment and Car-port within 30 (thirty) days of the dispatch of such notice.
8.3 That the allotment of the Car-port shall be made in accordance with the date of application of the 2nd Party for apartment after selecting the reservation of the Car-port for the Land-Owners.
8.4 That the 2nd Party’s failing to take possession within the time specified in the Notice, he shall be entitled to have formal possession of the demised Apartment and Car-port from the Developer within 60(sixty) days from the date of the Notice on payment of Caretaking Charge @ TK. 100.00 (taka one hundred) only per day of delay after the said period of 30 days for protecting, guarding and caretaking of the demised Apartment and Car-port on 2nd Party’s behalf. After the expiry of the said period of 60 days the Developer shall be absolved of every responsibility for giving possession and caretaking of demised Apartment and Car-port.
8.5 That the Land-owners and the Developer cease to have any connection with or responsibility for the Project or for any Apartment and Car-port thereof after completion of construction and handing over possession, whichever is later, of all the Apartment and Car-ports to his respective owners who shall be, thenceforth, jointly responsible for the use, occupation and maintenance of the Project as a whole and his respective premises including the operation, maintenance, repairs and replacement of the water lifting motors, pumps, water reservoirs, sewerage mains, electric mains, electric lines and installations, drains culverts, internal road and passages and other facilities, services and amenities.
9.0 TransferabilityThat the 2nd Party may transfer the Apartment,Car-port and share of ProjectLand allotted to him/her/them on acceptance of the developer before getting formal delivery of possession thereof and in default thereof.
10.0 Developer’s LibertyThat the Developer shall have a free hand in the construction of the Project including 2nd Party’s Apartment, Car-port and proportionate common facilities as integral parts thereoftogether with powers to make such minor alterations in the Plan/Designs and Specifications as may be deemed necessary and/or indispensable by the Developer and neither the 2nd Party nor the Land-Owners shall ever interfere with any such decisions, works, acts, deeds and things of the Developer without its consent except as otherwise be provided herein.
11.0 Mutual ObligationsThat its shall be the bounded duty of the Land-owners and the 2nd Party to accord whole-hearted co-operation to Developer in all lawful acts, deeds and things of or relating to the implementation of the Project and performance of this deal and of the Developer construct and deliver possession of the Apartment and Car-portswith common facilities to the former according to his respective entitlement in performance of the terms of this deal within the time-schedule specified therefore as far as practicable.
12.0 Apartment Owner’s statusThat without prejudice to any other provision of this instrument, the rights & status of the Apartment Owner’s interest, including the Land-owners and the 2nd Party, in respect of and in relation to his respective Apartment(s), Car-port (s), shares in common facilities shall be equal and pari passu and shares in project land will be in proportion of purchase of apartment space and common spaces.
13.0 Apartment Owners associationThe 2nd party will be bound to be a member of the apartment Owners Association as formed by the developer initially. The name of the apartment owners association will be “NIBASH JOTSNA Apartment Owners Association†i.e. “NJAOA†in short. The 2nd party must abide by the rules and regulation of the proposed association and its articles of memorandum and association. The 1nd party must deposit Taka 25,000/- as member ship fee in favor of the developer before taking over the possession from the developer. The developer shall hand over the total member ship amount in favor of the proposed association after formation of NJAOA.
14.0 Infallible terms of user14.1 That the Land-owners undertake and the 2nd Party agrees to possess, Occupy, maintain, use and enjoy his respectiveApartment and Car-ports and common facilities in association with the owners of otherApartment and Car-ports r of the Project.
14.2 That, he shall be a member of an Association, named Nibash Jotsna Apartment Owners’ Associationâ€, of all the Apartment Owners of the Project under a Committee of management thereof for purposes of the properadministration and managementof the affairs of the Project including maintenance, security, payment of rents, taxes & charges and enjoyment of common facilities by all owners on an equal and/or equitable footing. The common facilities for the Apartment Owners shall be, amongst other, the common corridors, lobbies, stairs and landings, common adjunct, fixtures, fitting, open space, the internal roads for entry & exit, passage, driveways, yards, drains, sewerage mains, sewer, water lifting motors and pumps, water reservoirs, electricity and gas connecting etc of the Project.
14.3 That in constituting and running of the said Association, the best norms of democratic methodology shall be strictly adhered to.
14.4 That no Apartment Owner shall have any liberty to keep off, withdraw or resign from the membership of the Association at any time during the subsistence of his/her/their ownership of an Apartment in the Project.
14.5 That the Association shall have a Reserve Fund to be contributed equally by all the owners of the Apartment of the Project in order to defray the expenses of day to day working of the Association.
14.6 That the use, occupation and enjoyment of the Apartment of the Project shall be subject to the following restrictions:-
(a) The 2nd Party shall not use the demised Apartment for any purpose other than residential purpose nor shall he use the demised Apartment in such manner as may cause or is likely to cause nuisance or annoyance to the owners of other Apartments.
(b) The 2nd Party shall not demolish or damage the demised Apartment nor shall make any structural alteration or raise any construction of any kind as an addition to or modification of the basic structure of demised Apartment.
(c) The 2nd Party shall not let out or transfer his Apartment to any person of ignoble conduct or social standing.
(d) The 2nd Party shall not use his Apartment for any illegal or immoral purposes or purposes harmful or prejudicial to good order and discipline.
(e) The 2nd Party shall not keep any domestic animal, such as dogs, cats, cows, goats or domestic birds like hens, ducks etc. in the apartment or within the premises.
(f) The 2nd Party shall not use or permit the use of the demised Apartment in a manner which might diminish the value of the Apartment(s), Carports and utilities.
(g) The 2nd Party shall not stock or display any materials in the corridors or in any place intended for common use of all the owners or occupiers of the apartment.
(h) The 2nd Party shall not display any business signboard, advertisement board or design, in any part of the demised Apartment.
14.7 That the 2nd Party who has been allotted a parking space as demarcated shall use such space as under: (a) That in order to keep the allotted parking space in good condition and for allowing free circulation of air and light, the parking space shall be used only for the purpose of parking the allotter’s own motor car or motor cycle or paddle cycle and for no other purpose.
(b) hat no side walls in the parking space shall be raised nor shall they be altered or modified in any manner.
(c) That no extra-roof or covering of any kind shall be made on the parking space.
(d) That notwithstanding anything contained elsewhere in this Agreement, the roofs of the building shall be used only for the purpose of providing water reservoirs and cloth drying area subject to decision of the Apartment Owners Association NJAOA.
15.0 Breach & RescissionThat the 2nd Party shall not be entitled to rescind or cause any breach of this Agreement, except on account of insolvency or inability to pay for Apartment concerned, without being liable to make instant payments to the Developer reasonable compensation for loss of business and good-will in addition to payments against the completed works of the project as per market value or cost-estimate thereof, whichever is higher, unless the Developer becomes, according to latter’s own judgment, incapable of implementing the Project.
16.0 Compensation That in the event of doing or causing to be done such acts, deeds and things of omission or commission by any of the parties hereto as shall result in sufferance of loss and injury by the other, the party suffering shall be entitled to demand and realize adequate amends therefore from the party at default and, if the party suffering be the Developer, to resign the Agreement in addition to demanding and receiving compensation.
17.0 Time & Force Majeure17.1 That the Developer shall complete the project within May 2011 from the date of commencing construction of the Project i.e. October 2009 to May 2011 and that, without prejudice to the specific provisions herein contained, "Time" shall be the essence of the contract unless the Developer be prevented from implementing the project within specified time by Force Majeure including but not limited to fire, storm, flood, earth quake, explosion, accident, military operation, war, rebellion, riot, wreck, epidemic, regulations and any laws, regulations or other Govt. Actions and situation beyond its control and/or the parties hereto mutually decide in writing for any reasonable cause or excuses to extend the time for any further specified period.
17.2 If for any reason of act of God including but not limited to fire, storm, flood, earthquake, explosion, accident, military operations, war, rebellion, riot, wreck, epidemic, regulations and any laws, regulations or other government actions and situations beyond its control, it does not become possible to process with building project and to complete the construction of the demised apartment, the Developer shall inform the 2nd Party whereupon the parties hereto shall by mutual discussion and consent make such additional provision as may be necessary to protect the interest of the parties.
18.0 Agreement with other than 2nd PartyThat this Agreement shall in no way debar or restrict the Developer in entering into similar agreements or deals with intending 2nd Party for other Apartments/Car-ports of the Project and also for the Apartment/Car-port allotted to the 2nd Party above named in the event of cancellation or termination of this deal.
19.0 Omission Coverage That if there are or appear to be anything concerning this deal as omitted or not specifically or by necessary implication visualized and covered, the parties hereto shall mutually determine it so as to be concomitant to the intents and the parties hereto.
20.0 Dispute & ArbitrationThat in the event of any dispute or difference arising between the parties hereto, the same shall be referred to arbitrators appointed in a manner hereinafter provided. The party raising the dispute shall serve a notice upon the other party advising that a dispute or difference has arisen and nominate in that notice its own arbitrator. The party receiving the notice shall, within 30(thirty) days after receiving such notice, nominates its arbitrator by advising the party raising the dispute and the name of the arbitrator appointed by the other party. The arbitrators so appointed shall appoint an umpire if necessary, in terms of the rules and meaning of Arbitration Act (Act X of 2001). The award of the arbitrators or umpire as the case may be, shall be final, conclusive and binding upon the parties hereto. Arbitration proceedings shall be conducted in accordance with the rules and meaning of Arbitration Act (Act X of 2001) and its statutory modification or re-enactment thereof in force from time to time. The venue of arbitration shall be decided by the arbitrators having regard to costs and convenience of the parties.
source: hubpages.com To be continue...